Commercial, Contractual and Adjudication Services Provided to the Main Contractor
Categories: Commercial, Contractual, Planning & Programming | Adjudication
Type of Project – Ultilities Services
The project consisted of the refurbishment and extension of existing office premises in city centre. The Contract sum was around £5m. The contract was a traditional JCT form of contract with the Employer’s (a developer) own team carrying out design.
Description of Issues
The main contractor had experienced substantial delays of approximately a year overall. Disputes arose about time and the application of liquidated damages. Disputes with several subcontractors arose over delays and the alleged lack of design information. Ramskill Martin represented the main contractor in 6 separate adjudications covering time and money.
Entitlements or Liabilities
An extension of time for the main contractor was established and claims were made. Liability for defective work became an issue and claims for approximately £1m. The developer could not ultimately meet his liabilities and Receivers were appointed.
Assistance to the Main Contractor
Ramskill Martin provided the main contractor with commercial, contractual and adjudication services. Ramskill Martin was able to successfully defend adjudications commenced by subcontractors and secured a favourable decision from the Adjudicator of an extension of time for part of the works of 21 out of the 25 weeks claimed.